Terms and Conditions

Company: Popular Consultants BD
Effective Date: September 1, 2026
Last Updated: September 1, 2026

Introduction

Welcome to Popular Consultants BD. These Terms and Conditions outline the rules and regulations for the use of our website and the engineering, consultancy, and turnkey services we provide.

By accessing this website and engaging our services, you accept these terms and conditions in full. Do not continue to use Popular Consultants BD if you do not agree to all the terms and conditions stated on this page.

1. Definitions

• • "Company", "We", "Our", "Us" refer to Popular Consultants BD.
  • "Client", "You", "Your" refers to the individual or business entity accessing this website or engaging our services.
  • "Services" refers to all engineering consultancy, fire safety audits, electrical assessments, structural safety audits, Annual Maintenance Contracts (AMC), and turnkey supply/installation solutions provided by us.

2. Use of the Website

• Accuracy of Information: While we strive to ensure the information on our website is accurate and up-to-date, engineering standards (such as BNBC, NFPA, and RSC guidelines) evolve. We do not warrant the completeness or accuracy of the material published on this website.
• Intellectual Property: Unless otherwise stated, Popular Consultants BD owns the intellectual property rights for all material on this website, including text, images, CAD design concepts, and blueprints. You may view and print pages for your own personal use, subject to restrictions set in these terms. You must not republish, sell, or reproduce our proprietary content without written consent.

3. Service Agreements and Project Execution

• Consultancy and Audits: Any structural, electrical, or fire safety audit provided by Popular Consultants BD is based on the visible and accessible conditions of the site at the time of inspection, alongside the data provided by the Client.
• Client Responsibilities: The Client agrees to provide accurate facility blueprints, historical safety data, and unobstructed site access required for our engineers to conduct thorough assessments and installations.
• Turnkey Installations: Delivery timelines and installation schedules for turnkey projects are estimates. We are not liable for delays caused by third-party shipping, customs, or unforeseen site complications (Force Majeure).

4. Limitation of Liability

To the maximum extent permitted by applicable law, Popular Consultants BD shall not be liable for any indirect, incidental, or consequential damages, including loss of business, revenue, or profits, arising out of the use of our website or the implementation of our consultancy advice.

While our designs and installations strictly aim to meet national and international compliance standards (BNBC, NFPA, RSC), the final approval and certification rest with the respective regulatory authorities. We do not guarantee the passing of third-party audits if the Client alters, neglects, or fails to properly maintain the installed systems (unless covered under an active AMC with us).

5. Annual Maintenance Contracts (AMC)

If you enter into an Annual Maintenance Contract with us, the specific scope of regular maintenance, emergency response times, and equipment coverage will be detailed in a separate, signed AMC agreement. These Terms and Conditions act as a supplement to any direct service contract.

6. External Links

Our website may contain links to third-party websites or resources. We do not endorse and are not responsible or liable for their availability, accuracy, or the related content.

7. Governing Law and Jurisdiction

These Terms and Conditions will be governed by and interpreted in accordance with the laws of Bangladesh. Any disputes relating to these terms will be subject to the exclusive jurisdiction of the courts of Dhaka, Bangladesh.

8. Changes to These Terms

We reserve the right to amend these Terms and Conditions at any time. By continuing to use the website and our services after modifications are posted, you agree to be bound by the updated terms.

9. Contact Us

If you have any questions or require further clarification regarding these Terms and Conditions, please contact us:

Email: info@popularconsultantsbd.com
Phone: +880 1911-866680
Website: www.popularconsultantsbd.com